ТОП просматриваемых книг сайта:
California Civil Code. California
Читать онлайн.Название California Civil Code
Год выпуска 0
isbn 9785392109821
Автор произведения California
Жанр Юриспруденция, право
Издательство Проспект
(b) If the claimant does not conform with the requirements of this chapter, the builder may bring a motion to stay any subsequent court action or other proceeding until the requirements of this chapter have been satisfied. The court, in its discretion, may award the prevailing party on such a motion, his or her attorney’s fees and costs in bringing or opposing the motion.
(Added by Stats. 2002, Ch. 722, Sec. 3. Effective January 1, 2003.)
931. If a claim combines causes of action or damages not covered by this part, including, without limitation, personal injuries, class actions, other statutory remedies, or fraud-based claims, the claimed unmet standards shall be administered according to this part, although evidence of the property in its unrepaired condition may be introduced to support the respective elements of any such cause of action. As to any fraud-based claim, if the fact that the property has been repaired under this chapter is deemed admissible, the trier of fact shall be informed that the repair was not voluntarily accepted by the homeowner. As to any class action claims that address solely the incorporation of a defective component into a residence, the named and unnamed class members need not comply with this chapter.
(Added by Stats. 2002, Ch. 722, Sec. 3. Effective January 1, 2003.)
932. Subsequently discovered claims of unmet standards shall be administered separately under this chapter, unless otherwise agreed to by the parties. However, in the case of a detached single family residence, in the same home, if the subsequently discovered claim is for a violation of the same standard as that which has already been initiated by the same claimant and the subject of a currently pending action, the claimant need not reinitiate the process as to the same standard. In the case of an attached project, if the subsequently discovered claim is for a violation of the same standard for a connected component system in the same building as has already been initiated by the same claimant, and the subject of a currently pending action, the claimant need not reinitiate this process as to that standard.
(Added by Stats. 2002, Ch. 722, Sec. 3. Effective January 1, 2003.)
933. If any enforcement of these standards is commenced, the fact that a repair effort was made may be introduced to the trier of fact. However, the claimant may use the condition of the property prior to the repair as the basis for contending that the repair work was inappropriate, inadequate, or incomplete, or that the violation still exists. The claimant need not show that the repair work resulted in further damage nor that damage has continued to occur as a result of the violation.
(Added by Stats. 2002, Ch. 722, Sec. 3. Effective January 1, 2003.)
934. Evidence of both parties’ conduct during this process may be introduced during a subsequent enforcement action, if any, with the exception of any mediation. Any repair efforts undertaken by the builder, shall not be considered settlement communications or offers of settlement and are not inadmissible in evidence on such a basis.
(Added by Stats. 2002, Ch. 722, Sec. 3. Effective January 1, 2003.)
935. To the extent that provisions of this chapter are enforced and those provisions are substantially similar to provisions in Section 6000, but an action is subsequently commenced under Section 6000, the parties are excused from performing the substantially similar requirements under Section 6000.
(Amended by Stats. 2012, Ch. 181, Sec. 30. Effective January 1, 2013. Operative January 1, 2014, by Sec. 86 of Ch. 181.)
936. Each and every provision of the other chapters of this title apply to general contractors, subcontractors, material suppliers, individual product manufacturers, and design professionals to the extent that the general contractors, subcontractors, material suppliers, individual product manufacturers, and design professionals caused, in whole or in part, a violation of a particular standard as the result of a negligent act or omission or a breach of contract. In addition to the affirmative defenses set forth in Section 945.5, a general contractor, subcontractor, material supplier, design professional, individual product manufacturer, or other entity may also offer common law and contractual defenses as applicable to any claimed violation of a standard. All actions by a claimant or builder to enforce an express contract, or any provision thereof, against a general contractor, subcontractor, material supplier, individual product manufacturer, or design professional is preserved. Nothing in this title modifies the law pertaining to joint and several liability for builders, general contractors, subcontractors, material suppliers, individual product manufacturer, and design professionals that contribute to any specific violation of this title. However, the negligence standard in this section does not apply to any general contractor, subcontractor, material supplier, individual product manufacturer, or design professional with respect to claims for which strict liability would apply.
(Amended by Stats. 2003, Ch. 762, Sec. 5. Effective January 1, 2004.)
937. Nothing in this title shall be interpreted to eliminate or abrogate the requirement to comply with Section 411.35 of the Code of Civil Procedure or to affect the liability of design professionals, including architects and architectural firms, for claims and damages not covered by this title.
(Added by Stats. 2002, Ch. 722, Sec. 3. Effective January 1, 2003.)
938. This title applies only to new residential units where the purchase agreement with the buyer was signed by the seller on or after January 1, 2003.
(Amended by Stats. 2003, Ch. 762, Sec. 6. Effective January 1, 2004.)
CHAPTER 5. Procedure [941 — 945.5]
(Chapter 5 added by Stats. 2002, Ch. 722, Sec. 3.)
941. (a) Except as specifically set forth in this title, no action may be brought to recover under this title more than 10 years after substantial completion of the improvement but not later than the date of recordation of a valid notice of completion.
(b) As used in this section, “action” includes an action for indemnity brought against a person arising out of that person’s performance or furnishing of services or materials referred to in this title, except that a cross-complaint for indemnity may be filed pursuant to subdivision (b) of Section 428.10 of the Code of Civil Procedure in an action which has been brought within the time period set forth in subdivision (a).
(c) The limitation prescribed by this section may not be asserted by way of defense by any person in actual possession or the control, as owner, tenant or otherwise, of such an improvement, at the time any deficiency in the improvement constitutes the proximate cause for which it is proposed to make a claim or bring an action.
(d) Sections 337.15 and 337.1 of the Code of Civil Procedure do not apply to actions under this title.
(e) Existing statutory and decisional law regarding tolling of the statute of limitations shall apply to the time periods for filing an action or making a claim under this title, except that repairs made pursuant to Chapter 4 (commencing with Section 910), with the exception of the tolling provision contained in Section 927, do not extend the period for filing an action, or restart the time limitations contained in subdivision (a) or (b) of Section 7091 of the Business and Professions Code. If a builder arranges for a contractor to perform a repair pursuant to Chapter 4 (commencing with Section 910), as to the builder the time period for calculating the statute of limitation in subdivision (a) or (b) of Section 7091 of the Business and Professions Code shall pertain to the substantial completion of the original construction and not to the date of repairs under this title. The time limitations established by this title do not apply to any action by a claimant for a contract or express contractual provision. Causes of action and damages to which this chapter does not apply are not limited by this section.
(Amended by Stats. 2003, Ch. 762, Sec. 7. Effective January 1, 2004.)
942. In order to make a claim for violation of the standards set forth in Chapter 2 (commencing with Section 896), a homeowner need only demonstrate, in accordance with the applicable evidentiary standard, that the home